Specifications include, but are not limited to:nstallation of access control equipment that will allow lock-down capability for various buildings across campus. This equipment will be operated by the Lenel Onguard access control platform. All exterior doors will have equipment installed or replaced and must be 100% compatible with Lenel OnGuard version 7.0 SP1 (7.0.1067) or later. All equipment must be part of a turnkey solution that will be operated by Lenel Onguard. See scope of work Exhibit A. 1.3Scope of Services; Acceptance of Contract Terms: As further described in Owner’s standard form Owner-Contractor Agreement, which is found at: http://www.uh.edu/legal-affairs/contract-administration/contract-documents/department-specific-contracts-and-forms/index.php#facilities (the“Contract Form”) the Contractor, if any, will provide construction services necessary to complete the Project within budget and on schedule. BY SUBMITTING A PROPOSAL,RESPONDENT IS EXPRESSLY CONSENTING TO THE TERMS, CONDITIONS AND PROVISIONS OF THE CONTRACT FORM. Any capitalized term used but not defined in this RFP has the meaning ascribed to it in the Contract Form. BYSUBMITTINGA PROPOSAL, RESPONDENT IS EXPRESSLY CONSENTING TO THE TERMS, CONDITIONS AND PROVISIONS OF THE CONTRACT FORM, INCLUDING THE BOND AND INSURANCE REQUIREMENTS DETAILED IN ARTICLE 12 OF THE CONTRACT. 1.3.1.1 Liquidated damages, as further explained in Section 3.2 of the Contract Form, will be assessed and offset against any amounts due and owing, or that become due, to Contractor as follows: Late Completion Day(s) Per Diem Amount 0-15 250.00 16-30 250.00 31+
