The City of Jacksonville is requesting BIDS for, Asbestos Removal Project at 14 Wardola Drive located in Jacksonville, North Carolina:
Description: The City of Jacksonville Asbestos Removal Project – 14 Wardola Drive
includes the abatement, removal and disposal of asbestos containing material as
identified in the attached report. The work includes all equipment, labor, material,
and services required for the City of Jacksonville Asbestos Removal Project – 14
Wardola Drive as described in the supplied project description, specifications and
drawings.
If you have any questions, or if you would like the complete bid document, please contact PAMELA TRAFTON
PROJECT MANAGER at PTRAFTON, or (910)938-6551
All bids are to be returned to PAMELA TRAFTON by 1:00 PM on May 3, 2021 at
the Front Desk at Jacksonville City Hall located at 815 New Bridge Street, Jacksonville,
NC 28540. There will not be a public bid opening. Bids can be mailed to Ms. Trafton’s attention at the above address,
emailed to ptrafton@jacksonvillenc.gov, or faxed to her at 910-938-5044. Any bid received after
the bid due date and time will be considered non-responsive.
The responsibility for submitting bids (including all documents requested herein) is solely and
strictly that of the bidder. The CITY is not responsible for delays in the delivery of the mail or
delays caused by any other occurrence. Bids received after the time for closing will not be
considered.
The CONTRACT DOCUMENTS may be examined and/or obtained at the Engineering Department at
Jacksonville City Hall located at 815 New Bridge Street, Jacksonville, NC 28540. Persons
requesting shipment of documents shall bear the additional, non-refundable cost of shipment.
The Jacksonville City Council reserves the right to waive any informalities, to reject any or all bids,
and to accept that Bid or Bids which appear to be in the Owner's best interest.
BID BOND: NOT REQUIRED
LICENSURE: BIDDERS must be properly licensed under Chapter 87 of the North Carolina General
Statutes.
E-VERIFY COMPLIANCE PROVISION: North Carolina General Statute §143-133.3 prohibits the
City from entering into contracts with contractors and subcontractors who have not complied with
the requirement of Article 2 of Chapter 64 of the North Carolina General Statutes. Contactor shall
comply with the requirements of Article 2 of Chapter 64 of the North Carolina General
Statutes. Further, if contractor utilizes a subcontractor, contractor shall require the subcontractor
to comply with the requirements of Article 2 of Chapter 64 of the North Carolina General Statutes.
EQUAL OPPORTUNITY: The City of Jacksonville is an Equal Opportunity Employer and Service
Provider and encourages participation by small-, minority-, and female-owned firms. Bidders
must make positive efforts to use Small or Minority Business enterprises. All qualified Small and
Minority businesses are welcome to submit a bid.
MINORITY BUSINESS PARTICIPATION: The CITY has established a verifiable goal of ten percent
(10%) for minority participation on City building construction and repair projects. In order to
foster participation by minority businesses to conduct business with the City and in accordance
with NCGS 143-131(b) and Resolution 1994-08, the City of Jacksonville will solicit minority
participation in all construction related contracts. Bidders shall undertake good faith efforts to
recruit minority business participation on this project. The minority business must be registered
with the North Carolina State Department of Administration, Office of Historically Underutilized
Businesses. BIDDER must complete and submit either Affidavit A or B with their Bid proposal.
RIGHT TO TERMINATE CONTRACT: If in the judgment of the Owner, the Contractor is not
capable of performing the desired work in accordance with the Contract documents either because
of financial reasons, failure to supply necessary skilled workmen, unsatisfactory tools or
equipment, inadequate supervision, or revocation of the Contractor's license, the Owner shall
have the right to cancel or terminate under this Contract by giving the Contractor seven (7) days
written notice.
CONTROLLING LAW: Any agreement, contract, or purchase order resulting from this invitation,
request for bid, quote, or request for proposal shall be governed by the laws of the State of North
Carolina.
If you have any questions, or if you would like the complete bid document, please contact PAMELA TRAFTON,
PROJECT MANAGER at PTRAFTON@jacksonvillenc.gov, or (910)938-6551.
See RFB for more information. RFB prevails over bidnet posting.
Statewide